A platform for research: civil engineering, architecture and urbanism
A platform for research: civil engineering, architecture and urbanism
Delay Analysis Techniques and Claim Assessment in Construction Projects
Abstract: The purpose of this research was to provide an understanding of what causes delays and claims in construction projects, along with the identification of multiple techniques that can be used for those issues causing delays. The true significance of this research lies in the bridging of gaps that were identified through a review of literature, along with the provision of essential findings based on a singular topic housing all of the associated variables so that every domain of related information could be explored and presented to the concerned people such as the construction management companies, project managers, and stakeholders of the construction project with better understanding on this topic. The methodology for this research revolved around the context of a quantitative approach, where a questionnaire was used for collecting data from more than 100 respondents in the dimension of multiple-choice questions so that a direct, and practical approach toward the understanding of said research topic could be developed. The results of this research revealed that most of the respondents viewed design, as well as consultant-related factors in the light of them being the highest impacting causes for delay and that the most probable technique which could be applied in the case of multiple delay causes was that of Time Impact Analysis or TIA. The construction stages through which these delay issues occur were also identified and listed individually for better understanding. Keywords: Delay analysis, Delay analysis techniques, Construction projects, Claim assessment. Title: Delay Analysis Techniques and Claim Assessment in Construction Projects Author: Amin Sherif, Ahmed Mohamed Abdelalim International Journal of Management and Commerce Innovations ISSN 2348-7585 (Online) Vol. 10, Issue 2, October 2022 - March 2023 Page No: 316-325 Research Publish Journals Website: www.researchpublish.com Published Date: 06-January-2023 DOI: https://doi.org/10.5281/zenodo.7509156 Paper Download Link (Source) ...
Delay Analysis Techniques and Claim Assessment in Construction Projects
Abstract: The purpose of this research was to provide an understanding of what causes delays and claims in construction projects, along with the identification of multiple techniques that can be used for those issues causing delays. The true significance of this research lies in the bridging of gaps that were identified through a review of literature, along with the provision of essential findings based on a singular topic housing all of the associated variables so that every domain of related information could be explored and presented to the concerned people such as the construction management companies, project managers, and stakeholders of the construction project with better understanding on this topic. The methodology for this research revolved around the context of a quantitative approach, where a questionnaire was used for collecting data from more than 100 respondents in the dimension of multiple-choice questions so that a direct, and practical approach toward the understanding of said research topic could be developed. The results of this research revealed that most of the respondents viewed design, as well as consultant-related factors in the light of them being the highest impacting causes for delay and that the most probable technique which could be applied in the case of multiple delay causes was that of Time Impact Analysis or TIA. The construction stages through which these delay issues occur were also identified and listed individually for better understanding. Keywords: Delay analysis, Delay analysis techniques, Construction projects, Claim assessment. Title: Delay Analysis Techniques and Claim Assessment in Construction Projects Author: Amin Sherif, Ahmed Mohamed Abdelalim International Journal of Management and Commerce Innovations ISSN 2348-7585 (Online) Vol. 10, Issue 2, October 2022 - March 2023 Page No: 316-325 Research Publish Journals Website: www.researchpublish.com Published Date: 06-January-2023 DOI: https://doi.org/10.5281/zenodo.7509156 Paper Download Link (Source) ...
Delay Analysis Techniques and Claim Assessment in Construction Projects
Amin Sherif (author) / Ahmed Mohamed Abdelalim (author)
2023-01-06
oai:zenodo.org:7509156
International Journal of Management and Commerce Innovations 10(2) 316-325
Article (Journal)
Electronic Resource
English
DDC:
690
DELAY ANALYSIS TECHNIQUES IN CONSTRUCTION PROJECTS
| TIBKAT | 2019
Claim-Avoidance Administrative Procedures for Construction Projects
| British Library Conference Proceedings | 2000
Calculating method of construction delay cost claim in China
| Tema Archive | 1998
Performance Indicators for the Claim Management Process of Construction Projects
| British Library Conference Proceedings | 2019